The Connecticut Appellate Court recently issued a decision that should cause every contractor some concern.  In J. WM. Foley Inc. v. United Illuminating Co., 158 Conn. App. 27 (Conn.App. 2015), the Appellate Court upheld a decision that denied a contractor’s $4.7 million delay claim because the contractor did not provide proper notice of the claim within the 10 days required by the contract.  The case is disconcerting because the court’s decision appears to be based upon the contractor’s failure to strictly comply with the contract’s notice provision.  There is no discussion indicating that the owner was harmed or prejudiced by the delay in receiving notice of the claim.  Moreover, the decision acknowledges that the contractor had provided the owner with notice of events giving rise to the claim.  In fact, despite denying the delay claim, the trial court awarded the plaintiff over one million dollars for its direct costs, which arose out of the same facts as the delay claim.

The project underlying the dispute in J. WM. Foley Inc. was the construction of a utility pipeline.  The parties’ agreement stated that the contractor was expected to encounter subsurface obstructions and that the contractor would be entitled to additional compensation associated with same.