Notice Archives - Attorney Scott S. Orenstein | Construction Law & Litigation

The Importance of Reading and Understanding Your Construction Contract

Everyone knows that they ought to eat right and exercise; yet, far too few of us do it. Similarly, proper construction contract management requires a contractor to thoroughly understand their contracts but many fail to do so. Of course, the reason that contractors are often largely ignored are understandable. Most construction contracts have the same substantive provisions with which contractors are already familiar; the specific requirements for any given project will be discussed at the preconstruction meeting; and the more specific details of any contract tend to only really matter in the rare occasions that the parties end up in a dispute they cannot resolve on their own. However, the few instances that result in litigation may make having proper practices in place for every project worthwhile.

On a positive note, most contractors that I encounter are now reading their contracts before signing them, as opposed to only reading them after a problem develops. As obvious as this may sound, actually taking the time to thoroughly read a contract before a project begins is the only way to be certain that you will fully comply with all your obligations. In addition, reading a contract before signing can prevent a contractor from experiencing an unfortunate surprise.

Recent Decision Demonstrates the Importance of Complying with Contract Notice Provisions

A common provision in construction contracts requires a contractor to give notice to the owner within a certain number of days of an event giving rise to a claim. Such provisions have a reasonable basis insofar as they ensure an owner will have a reasonable opportunity to investigate the conditions for which a claim for additional compensation is being made. Traditionally, such notice provisions were not strictly enforced. The general approach seemed to be that — provided the owner was not prejudiced by any delay in giving notice of claim — a claim that was not submitted within the specified time limit would not be barred. The more recent trend, however, has been to more strictly construe such provisions.

In J. Wm. Foley, Inc. v. United Illuminating, the Appellate Court held that the contractor’s failure to submit its delay claim within the ten-day time limit specified by the contract was a bar to the claim. This decision is potentially troublesome for a couple of reasons: First, there is no reference to the owner suffering any prejudice as a result of the delay. Second, the decision indicated that the submission of the delay claim required a critical path analysis of the delay.

Contractual Time Limits for Providing Notice of Claim Must be Taken Seriously

The Connecticut Appellate Court recently issued a decision that should cause every contractor some concern. In J. WM. Foley Inc. v. United Illuminating Co., 158 Conn. App. 27 (Conn.App. 2015), the Appellate Court upheld a decision that denied a contractor’s $4.7 million delay claim because the contractor did not provide proper notice of the claim within the 10 days required by the contract. The case is disconcerting because the court’s decision appears to be based upon the contractor’s failure to strictly comply with the contract’s notice provision. There is no discussion indicating that the owner was harmed or prejudiced by the delay in receiving notice of the claim. Moreover, the decision acknowledges that the contractor had provided the owner with notice of events giving rise to the claim. In fact, despite denying the delay claim, the trial court awarded the plaintiff over one million dollars for its direct costs, which arose out of the same facts as the delay claim.

The project underlying the dispute in J. WM. Foley Inc. was the construction of a utility pipeline. The parties’ agreement stated that the contractor was expected to encounter subsurface obstructions and that the contractor would be entitled to additional compensation associated with same.

With Payment Bond Claims, Different Rules Apply to the Bond Claimant and the Surety

As previously discussed in this Blog, Conn. Gen. Stat. § 49-41 requires each general contractor on a public works projects valued over $100,000 to post a payment bond that guarantees payment to the general contractor’s subcontractors and suppliers. The payment bond also guarantees payment to each subcontractors’ sub-subcontractors and suppliers.

The procedure by which such subcontractors, sub-subcontractors, and/or suppliers may make claim against such payment bonds is described in Conn. Gen. Stat. § 49-42. With the exception of claims for retainage, the statute requires those making claim on the payment bond to submit their “notice of claim” within 180 calendar days after the last day that it worked and/or supplied materials. The statute then provides the surety that issued the payment bond with 90 calendar days to pay or deny the claim. Until recently, both time provisions were mandatory. See Barreira Landscaping & Masonry v. Frontier Ins. Co., 47 Conn. Supp. 99, 110, 779 A.2d 244, 252 (Super. Ct. 2000)(holding that both the notice of claim and the surety’s response both much be made within the time specified by statute.)

With regard to the 90 day time limit, the court in Barreira Landscaping &

Categories

Recent Posts