Contractual Time Limits for Providing Notice of Claim Must be Taken Seriously

The Connecticut Appellate Court recently issued a decision that should cause every contractor some concern.  In J. WM. Foley Inc. v. United Illuminating Co., 158 Conn. App. 27 (Conn.App. 2015), the Appellate Court upheld a decision that denied a contractor’s $4.7 million delay claim because the contractor did not provide proper notice of the claim within the 10 days required by the contract.  The case is disconcerting because the court’s decision appears to be based upon the contractor’s failure to strictly comply with the contract’s notice provision.  There is no discussion indicating that the owner was harmed or prejudiced by the delay in receiving notice of the claim.  Moreover, the decision acknowledges that the contractor had provided the owner with notice of events giving rise to the claim.  In fact, despite denying the delay claim, the trial court awarded the plaintiff over one million dollars for its direct costs, which arose out of the same facts as the delay claim.

 

The project underlying the dispute in J. WM. Foley Inc. was the construction of a utility pipeline.  The parties’ agreement stated that the contractor was expected to encounter subsurface obstructions and that the contractor would be entitled to additional compensation associated with same. 

Beware of No Damages for Delay Clauses

It is common for construction contracts to state that, if the project is delayed by the owner, the contractor shall be entitled to an extension of contract time but will not be entitled to any addition compensation.  Such a contract provision is known as a “no damages for delay” clause.  The Connecticut Supreme Court has held that “‘no damages for delay’ clauses are generally valid and enforceable and are not contrary to public policy. [unless]: (1) [the] delays [are] caused by the [owner’s] bad faith or its willful, malicious, or grossly negligent conduct, (2) [the delays] uncontemplated …, (3) [the] delays so unreasonable that they constitute an intentional abandonment of the contract …, and (4) [the] delays [result] from the [owner’s] breach of a fundamental obligation of the contract.  White Oak Corp. v. Department of Transp., 217 Conn. 281, 288-89, 585 A.2d 1199, 1203 (Conn.,1991).  The list of exceptions; however, may not actually be that broad.  In a recent decision, the Superior Court analyzed the applicability of the aforesaid exceptions to a typical “no damages for delay” clause.

In C & H Elec., Inc. v. Town of Bethel, an electrical contractor was substantially delayed because of the additional asbestos abatement work that was required. 

Understanding Unabsorbed Home Office Overhead

It is readily apparent that – if a project is delayed – the contractor is losing money.  The increased direct costs associated with the labor and equipment on site are obvious. The more complex question arises when considering the effect a delayed project has on a contractor’s recovery of its home office overhead, where “home office overhead” is defined as the cost of the contractor’s main office including, but not limited to, rent, utilities, executive and management salaries, staff, office equipment, office supplies, taxes, insurance, etc.  Everyone intuitively understands that a delayed project increases such costs in the same manner that that delays increase the project’s direct costs but increases in home office overhead cannot be directly correlated to any one project because a contractor typically has several projects with overlapping schedules underway at any given time.  Over the years, courts have attempted to determine the damages necessary “to compensate a contractor for its indirect costs that cannot be allocated to a particular contract for the period during which the government has made contractual performance impossible.”  Charles G. Williams Constr., Inc. v. White, 326 F.3d 1376, 1380-1381 (Fed. Cir. 2003).  “As a result, there are at least nine formulas that have been used,