Here’s Some General Information for Those Wishing to File Their Own Mechanic’s Lien in Connecticut (Including a Mechanic’s Lien Form)

As a disclaimer, I don’t recommend that contractors file their own mechanic’s liens without the aid of an attorney. Every client and/or potential client that has ever come to me asking that I foreclose a mechanic’s lien that they filed on their own had some fatal defect. The reason for that is the arguably conflicting laws in the statutes and in the court decisions interpreting those laws.

A prime example of something that is not readily apparent by reading the mechanic’s lien laws is the notice and service requirements. According to our courts, “[r]ead together, [Sections] 49-34 and 49-35 [of the Connecticut General Statutes] require the [contractor filing the lien] to serve a copy of the certificate upon each owner of the property within 90 days after he ceased performing services or furnishing materials.” Steeltech Bldg. Prod., Inc. v. Viola, 2000 WL 726367, at *2 (Conn. Super. Ct. May 16, 2000). Of course, one may not reach that same conclusion reading [Sections] 49-34 and 49-35 on their own. According to Connecticut General Statutes § 49-34, “[a] mechanic’s lien is not valid unless the person performing the services or furnishing the materials [records a certificate of mechanic’s lien in the land records] within ninety days after he has ceased to do so…” However,

The Importance of Reading and Understanding Your Construction Contract

Everyone knows that they ought to eat right and exercise; yet, far too few of us do it. Similarly, proper construction contract management requires a contractor to thoroughly understand their contracts but many fail to do so. Of course, the reason that contractors are often largely ignored are understandable. Most construction contracts have the same substantive provisions with which contractors are already familiar; the specific requirements for any given project will be discussed at the preconstruction meeting; and the more specific details of any contract tend to only really matter in the rare occasions that the parties end up in a dispute they cannot resolve on their own. However, the few instances that result in litigation may make having proper practices in place for every project worthwhile.

On a positive note, most contractors that I encounter are now reading their contracts before signing them, as opposed to only reading them after a problem develops. As obvious as this may sound, actually taking the time to thoroughly read a contract before a project begins is the only way to be certain that you will fully comply with all your obligations. In addition, reading a contract before signing can prevent a contractor from experiencing an unfortunate surprise.

WHAT TO DO WHEN YOU ARE NOT BEING PAID

The most common issue I confront as a construction attorney is what to do when my client is not being paid. The standard approaches include sending a demand letter, making a demand for disputed funds to be placed in escrow in accordance with the prompt payment statute, and, of course, filing mechanic’s liens and/or bond claims. The larger issue becomes what to do when my client can no longer to perform its work without payment.

As a general rule, a contractor is better off completing its work, and then fighting about the monies due, as opposed to walking off the job. While it is true that there are Connecticut cases which hold that a contractor is excused from finishing its work if progress payments are not made when due, but reliance on such cases is fraught with potential problems.

If you ever forced to litigate, you want to be viewed as the one wearing the white hat. You want to be the injured party that is as pure as the driven snow. If at all possible, you do not want to give the other side any arguments to raise. Thus, if you walk off the job for nonpayment,

Remedial Work Does Not Extend the Deadline to Commence an Action on a Payment Bond

As most contractors are aware, if they are not paid for their labor, materials, and/or services, they can strengthen their position prior to filing a lawsuit by filing a mechanic’s lien, or by making a claim against the project’s bond claim. Of course, both options are not generally available. Typically, the choice is based upon whether the project is private or public. On private projects, a contractor (or supplier) is allowed to gain a security interest in the property by filing a mechanic’s lien. On public projects, federal and local governments passed laws requiring the general contractor on public projects to post “payment bonds,” which guarantee the payment of those who supply labor, materials, and/or services to the property. In other words, because governments were not willing to let public lands be subject to foreclosure, on public projects, statutorily required payment bonds were created to take the place of mechanic’s liens. Of course, private owners may require general contractors to post payment bonds on private projects as well, but this post only addresses the statutory payment bonds required on public projects.

The law that requires payment bonds on federal projects is known as the Miller Act. The various state laws that require payment bonds on state projects are often referred to as “Little Miller Acts.” The requirements are the Miller Act and the various Little Miller Acts are generally similar.

Slander of Title is Almost Always an Inappropriate Response to a Mechanic’s Lien

On rare occasions, I have had to contend with a claim of “slander of title” being filed in response to a mechanic’s lien. A slander of title claim requires:

  • The making of a false statement pertaining to the owner’s title;
  • The making of the false statement must have been made “with malice”; and
  • The false statement must result in actual damages.

Neri Corp. v. McDermott Rd., LLC, 2016 Conn. Super. LEXIS 2067, *18 (Conn. Super., July 26, 2016). The requirement for the statement to have been made “with malice” means that the lienor either had acknowledged that the statements in its mechanic’s lien were false or that the lienor acted with “a reckless disregard of the truth.” Id. Both are very unlikely in the context of a mechanic’s lien.

As stated previously in this blog, the purpose of a mechanic’s lien is to provide security for an alleged debt arising out of work performed. Notwithstanding the foregoing, the “[f]iling of a mechanic’s lien like that of any other lien can be the basis of a slander of title action as long as all of the elements of the tort are met.” Id.

Recent Decision Demonstrates the Importance of Complying with Contract Notice Provisions

A common provision in construction contracts requires a contractor to give notice to the owner within a certain number of days of an event giving rise to a claim. Such provisions have a reasonable basis insofar as they ensure an owner will have a reasonable opportunity to investigate the conditions for which a claim for additional compensation is being made. Traditionally, such notice provisions were not strictly enforced. The general approach seemed to be that — provided the owner was not prejudiced by any delay in giving notice of claim — a claim that was not submitted within the specified time limit would not be barred. The more recent trend, however, has been to more strictly construe such provisions.

In J. Wm. Foley, Inc. v. United Illuminating, the Appellate Court held that the contractor’s failure to submit its delay claim within the ten-day time limit specified by the contract was a bar to the claim. This decision is potentially troublesome for a couple of reasons: First, there is no reference to the owner suffering any prejudice as a result of the delay. Second, the decision indicated that the submission of the delay claim required a critical path analysis of the delay.

A Mechanic’s Lien: Something Simple That’s Been Made Complicated

One of the first things I was ever taught about mechanic’s liens is that the legislation’s original intent was for a contractor to be able to perfect a mechanic’s lien without the aid of an attorney. If that’s true, the system is not working as intended. Of course, that is not surprising given the complicated legislation and its arguably inconsistent interpretation.

A mechanic’s lien is unique insofar as it allows a contractor to obtain an interest in real property without requiring any kind of hearing or notice. As long as the lien documents are properly prepared, recorded, and served, the lien is in place. In addition, the fact that mechanic’s liens have priority dates that relate back to the first day that the contractor performs work and/or supplies materials, mechanic’s liens that did not exist when a mortgage was given or the property was sold can appear on the land records after such transactions and take priority over an earlier filed mortgage and/or encumber property owned by someone who was not the property owner at the time the work was performed, materials were supplied and/or services were rendered.

Of course, reading the statutes is not sufficient to completely understand mechanic’s liens.

A Recent Supreme Court Decision Found an Owner of a Construction Company Personally Liable to the Owners of a Project

As most people are aware, one of the benefits of doing business as a corporation or limited liability company is that, generally speaking, the owners of the company cannot be held personally liable for the company’s debts. The exception to that general rule is that a court may pierce the corporate veil and hold the company owners personally liable if the company owners are found to have improperly used the corporate form, or have used the corporate form to commit wrongful acts. Nonetheless, even a cursory of the caselaw indicates that plaintiffs do not often prevail when they are attempting to pierce the corporate veil.

The statement of the law with regard to piercing the corporate view is quite simple. In All Phase Builders, LLC v. New City Rests., 2011 Conn. Super. LEXIS 1793, *20-21, 2011 WL 3483368 (Conn. Super. Ct. July 12, 2011), the court ruled:

“In order to pierce the corporate veil, a plaintiff must plead and prove that the corporate shield can be pierced under either the instrumentality rule or the identity rule. The instrumentality rule requires… proof of three elements: (1) Control …; (2) that such control must have been used by the defendant to commit fraud or wrong …;

Contractual Time Limits for Providing Notice of Claim Must be Taken Seriously

The Connecticut Appellate Court recently issued a decision that should cause every contractor some concern.  In J. WM. Foley Inc. v. United Illuminating Co., 158 Conn. App. 27 (Conn.App. 2015), the Appellate Court upheld a decision that denied a contractor’s $4.7 million delay claim because the contractor did not provide proper notice of the claim within the 10 days required by the contract.  The case is disconcerting because the court’s decision appears to be based upon the contractor’s failure to strictly comply with the contract’s notice provision.  There is no discussion indicating that the owner was harmed or prejudiced by the delay in receiving notice of the claim.  Moreover, the decision acknowledges that the contractor had provided the owner with notice of events giving rise to the claim.  In fact, despite denying the delay claim, the trial court awarded the plaintiff over one million dollars for its direct costs, which arose out of the same facts as the delay claim.

 

The project underlying the dispute in J. WM. Foley Inc. was the construction of a utility pipeline.  The parties’ agreement stated that the contractor was expected to encounter subsurface obstructions and that the contractor would be entitled to additional compensation associated with same. 

Only the “Owner” may seek Judicial Discharge of Mechanic’s Liens

The Connecticut Superior Court recently decided a case of first impression regarding the right to file an application for discharge of mechanic’s liens.  The court in Grade A Mkt., Inc. v. Surplus Contrs., LLC held that a lessee did not have “standing” to file an application for discharge of mechanic’s liens and dismissed the tenant’s application.  Grade A Mkt., Inc. v. Surplus Contrs., LLC, 2015 Conn. Super LEXIS 1342 (Conn. Super. May 26, 2015).  In layman’s terms, “standing” is the right to have the court decide your case.  The Grade A Mkt decision is interesting because it limits the ability of a tenant to obtain a discharge of mechanic’s liens even though the tenant’s lease with the owner may require the tenant to obtain a discharge of mechanic’s liens filed by contractors performing work for the tenant.

Mechanic’s liens are a statutory right that the legislature created to provide contractors and/or suppliers that furnish labor, materials, and/or services to a property with security for the alleged debt but mechanic’s liens were not intended to prevent the free transfer of property rights.  For that reason, the statutes provide a few different mechanisms by which an appropriate individual or company may obtain a release of the mechanic’s lien.