A RECENT APPELLATE DECISION THAT PURPORTS TO EXPLAIN THE MEANING OF “CARDINAL CHANGE” ACTUALLY ONCE AGAIN DEMONSTRATES THE IMPORTANCE OF NEGOTIATING A FAIR CONTRACT

Change order provisions, which appear in most constructon contracts and contemplate changes being made to the work, contradict a fundamental premise of contract law.  Specifically, in order for there to be a legally enforceable agreement, “there must be mutual assent or a meeting of the minds.”  C.A.D.S., LLC v. Sundance Realty, LLC, 2019 Conn. Super. LEXIS 29, *25 (July 2, 2018).  A contract is supposed to be “based on an identical understanding of the parties.” Id. at *25-26.  Yet, as anyone in construction is aware, the project owner may order changes during the performance of the work that the contractor is contractually bound to perform, subject to appropriate adjustments in monetary compensation and the time to complete the work.

Notwithstanding the foregoing, there are limits in an owner’s ability to order changes in the work, because the owner is not allowed to require a contractor to perform “cardinal changes.”  “A ‘cardinal’ change is a change outside the general scope of the contract.”  Philip L. Bruner & Patrick J. O’Connor, Jr., Bruner & O’Connor on Construction Law § 4:13.  The significance of a cardinal change is that it is not covered by a standard change order provision. 

When the Breach of a Construction Contract is not a Breach

The doctrine of substantial performance holds that a contractor’s breach of a construction contract does not entitle the owner to damages because the contractor’s performance was close enough to that which the contract required. “Technical violations are excused not because compliance [is] impossible, but because actual performance is so similar to the required performance that any breach that may have been committed is immaterial. Substantial performance occurs when, although the conditions of the contract have been deviated from in trifling particulars not materially detracting from the benefit the other party would derive from a literal performance, [the other party] has received substantially the benefit [it] expected, and is, therefore, bound to perform.” United Concrete Prod., Inc. v. NJR Constr., LLC, No. CV176011932S, 2018 WL 5733720, at *4 (Conn. Super. Ct. Oct. 17, 2018). The classic example of this doctrine is a situation where the contract specifies a product manufactured by Company A but the contractor provides the same product manufactured by Company B. Because the contract expressly stated that the product shall be manufactured by Company A, the installation of the same product manufactured by a different company is a breach of the contract. However, because the products are identical other than the name of the manufacturer,

The Importance of Reading and Understanding Your Construction Contract

Everyone knows that they ought to eat right and exercise; yet, far too few of us do it. Similarly, proper construction contract management requires a contractor to thoroughly understand their contracts but many fail to do so. Of course, the reason that contractors are often largely ignored are understandable. Most construction contracts have the same substantive provisions with which contractors are already familiar; the specific requirements for any given project will be discussed at the preconstruction meeting; and the more specific details of any contract tend to only really matter in the rare occasions that the parties end up in a dispute they cannot resolve on their own. However, the few instances that result in litigation may make having proper practices in place for every project worthwhile.

On a positive note, most contractors that I encounter are now reading their contracts before signing them, as opposed to only reading them after a problem develops. As obvious as this may sound, actually taking the time to thoroughly read a contract before a project begins is the only way to be certain that you will fully comply with all your obligations. In addition, reading a contract before signing can prevent a contractor from experiencing an unfortunate surprise.

WHAT TO DO WHEN YOU ARE NOT BEING PAID

The most common issue I confront as a construction attorney is what to do when my client is not being paid. The standard approaches include sending a demand letter, making a demand for disputed funds to be placed in escrow in accordance with the prompt payment statute, and, of course, filing mechanic’s liens and/or bond claims. The larger issue becomes what to do when my client can no longer to perform its work without payment.

As a general rule, a contractor is better off completing its work, and then fighting about the monies due, as opposed to walking off the job. While it is true that there are Connecticut cases which hold that a contractor is excused from finishing its work if progress payments are not made when due, but reliance on such cases is fraught with potential problems.

If you ever forced to litigate, you want to be viewed as the one wearing the white hat. You want to be the injured party that is as pure as the driven snow. If at all possible, you do not want to give the other side any arguments to raise. Thus, if you walk off the job for nonpayment,

Recent Decision Demonstrates the Importance of Complying with Contract Notice Provisions

A common provision in construction contracts requires a contractor to give notice to the owner within a certain number of days of an event giving rise to a claim. Such provisions have a reasonable basis insofar as they ensure an owner will have a reasonable opportunity to investigate the conditions for which a claim for additional compensation is being made. Traditionally, such notice provisions were not strictly enforced. The general approach seemed to be that — provided the owner was not prejudiced by any delay in giving notice of claim — a claim that was not submitted within the specified time limit would not be barred. The more recent trend, however, has been to more strictly construe such provisions.

In J. Wm. Foley, Inc. v. United Illuminating, the Appellate Court held that the contractor’s failure to submit its delay claim within the ten-day time limit specified by the contract was a bar to the claim. This decision is potentially troublesome for a couple of reasons: First, there is no reference to the owner suffering any prejudice as a result of the delay. Second, the decision indicated that the submission of the delay claim required a critical path analysis of the delay.

Design Professional Liability Raises Interesting Questions

Today, in many instances, the design/bid/build project delivery system has been modified through the use of construction managers (either at-risk or advisors) and owner’s representatives, or has been entirely usurped by a design-build arrangement. However, there are still many projects constructed using the traditional approach, where an owner first contracts with a design professional (either an engineer or an architect); the design professional then prepares a complete set of construction documents that the prospective general contractors rely upon to submit their bids; and the owner awards the contract for the project’s construction to the successful general contractor. The general contractor, in turn, hires various subcontractors and suppliers who then hire their sub-subcontractors and suppliers. As a result, there are a great number of individuals and entities relying upon the design professional’s work. The question is whether all these individuals and entities may hold the design professional liable for its negligence.

This blog post will focus on the traditional design/bid/build approach, but the principles stated herein can be applied to other delivery methods.

Under the traditional approach, one may expect that the owner could hold the design professional liable for any damages it incurs arising from defective plans and specifications by virtue of their contractual relationship but that is not the case.

A Recent Supreme Court Decision Found an Owner of a Construction Company Personally Liable to the Owners of a Project

As most people are aware, one of the benefits of doing business as a corporation or limited liability company is that, generally speaking, the owners of the company cannot be held personally liable for the company’s debts. The exception to that general rule is that a court may pierce the corporate veil and hold the company owners personally liable if the company owners are found to have improperly used the corporate form, or have used the corporate form to commit wrongful acts. Nonetheless, even a cursory of the caselaw indicates that plaintiffs do not often prevail when they are attempting to pierce the corporate veil.

The statement of the law with regard to piercing the corporate view is quite simple. In All Phase Builders, LLC v. New City Rests., 2011 Conn. Super. LEXIS 1793, *20-21, 2011 WL 3483368 (Conn. Super. Ct. July 12, 2011), the court ruled:

“In order to pierce the corporate veil, a plaintiff must plead and prove that the corporate shield can be pierced under either the instrumentality rule or the identity rule. The instrumentality rule requires… proof of three elements: (1) Control …; (2) that such control must have been used by the defendant to commit fraud or wrong …;

Mechanic’s Liens – Legislative Update

Every year, state legislatures across the country pass new laws and revise old ones.  In fact, these state legislatures often tinker with existing statutes that have been in place for many years and are working as intended.  This year, the Connecticut legislature has raised a bill, Raised Bill No. 887, “An Act Concerning the Requirements for the Filing of a Mechanic’s Lien” (the “Act”), that may have an adverse effect on the construction industry through unintended consequences.

The Act would add a new requirement for a mechanic’s lien to be valid.  Specifically, the Act states that the contractor performing the work must hold “the appropriate registration or license to perform the services.”  On one hand, the Act has the valid purpose of discouraging unlicensed individuals from performing construction services.  On the other hand, this revision to the mechanic’s lien laws would be duplicative of the laws and regulations pertaining to licensure already in place insofar as the existing laws and regulations prohibit certain work from being performed without a license.  In addition, the mechanic’s lien statutes are not the best place to address this issue.

The mechanic’s lien laws were established in all fifty states to provide contractors and suppliers with recourse in the event of nonpayment for their labor,

An Explanation of The Home Improvement Act’s Licensed Contractor Exception

Chapter 400 of the Connecticut General Statutes is known as the Home Improvement Act.  “The purpose of the Home Improvement Act is to ensure that home improvements are performed by qualified people.”  Santa Fuel, Inc. v. Varga, 77 Conn.App. 474, 495 (Conn.App.,2003).  A “[h]ome improvement contract” means an agreement between a contractor and an owner for the performance of a home improvement.”  Conn. Gen. Stat. § 20-419.  As a general rule, a home improvement contract is not enforceable against a homeowner unless the contract complies with the writing requirements of the Home Improvement Act.  Laser Contracting, LLC v. Torrance Family Ltd. Partnership, 108 Conn.App. 222, 226, (Conn.App.,2008).

The Home Improvement Act serves a valid purpose but may be heavy handed in its application.  In holding that the failure to comply with the statutory requirements for a home improvement contract bars all recovery, including claims sounding in implied contract and unjust enrichment, the Connecticut Supreme Court said the following:

We recognize that our decision may lead to a harsh result where a contractor in good faith but in ignorance of the law performs valuable home improvements without complying with § 20-429. 

Construction Claims May Come From A Variety of Sources

Most construction claims arise out of the contractual relationship between the parties.  Some arise out of claims of negligence.  There are other situations where a contractor may be held liable for damages that stem from nothing more than having engaged in certain activities.  Such claims are based upon the idea that “strict liability” applies to “ultra-hazardous activities.”  In both situations, i.e. claims based upon negligence and claims based upon strict liability, the first party performs an act or omission that results in damage to the life or property of the second party.  With a negligence claim, in order to be held liable, the first party must owe the second party a duty that is breached by the first party’s act or omission.  For example, if a contractor is working on scaffolding above a sidewalk, the contractor must use reasonable care to make sure that nothing falls on the people below and, in that situation, the contractor would only be held liable if something fell due to the failure to exercise reasonable care and not solely because something fell.  With a strict liability claim, however, all that is required is for the contractor to be held liable is for the contractor to be engaged in the activity that caused the harm.